Project
Ontario Community College - B2 (Demo Data)
CPP
CRITICAL PATH PARTNERSForensic Schedule Analysis
DWG · CCDC 2 - 2020, Contract No. OCC-B2-2025 (Demo Data) / SHEET A-00
Claims Package · Cover Letter · Rev A
Extension of Time Claim
Claims Package Cover Letter Ontario Community College - B2 (Demo Data) · CCDC 2 - 2020, Contract No. OCC-B2-2025 (Demo Data)
Total Time Claimed
9
Working days EOT requested
Delay Event
1
Exhibits
4
Response
30 DAYS
A-01
Claim Headline
summary of relief requestedTime Claimed
9 WD
total working days
Delay Events
1
analysed in Exhibit DE-01
Supporting Docs
5
documents indexed
Response Window
30 DAYS
written response requested
A-02
Correspondence Block
claimant · recipient · subjectFrom · Claimant
CompanyNorthgate Constructors
Address400 Example Road, Toronto, Ontario (Demo)
DateSeptember 01, 2026
To · Recipient
AttentionMs. R. Chen, Owner's Representative (Demo)
CompanyOntario Community College Owner Group
Address1 College Drive, Toronto, Ontario (Demo)
Subject · Reference
REEOT Claim: Ontario Community College - B2 (Demo Data)
ContractCCDC 2 - 2020, Contract No. OCC-B2-2025 (Demo Data)
BasisGC 6.5.1 (delay by the Owner or the Consultant)
A-03
Statement of Claim
opening narrativeRequest for Relief
Northgate Constructors hereby submits a request for extension of time totalling 9 working days for the above-referenced project. Each delay event is documented in a separate exhibit referenced below.
The Contractor claims 9 working days pursuant to GC 6.5.1 (delay by the Owner or the Consultant) of the demonstration contract. Clause citations follow the demonstration contract and are stated for format; this is synthetic data.
Time Claimed
9 WD
Delay Events
1
Exhibits
4
Total Claimed
EOT REQUESTED
Critical-path impact: owner-directed change
A-04
Exhibit Index
register · all exhibits listedA-04Exhibit Index: every exhibit in the package
4 exhibits — all listedExport CSV
| Exhibit | Title | File |
|---|---|---|
| A | Cover Letter (this document) | — |
| DE-01 | Delay Event Analysis: Fire-spray application held for owner inspector availability | Ontario_Community_College___B2_Demo_Data_Exhibit_DE-01_Fire_spray_application_held_for_owner_inspector_availability.docx |
| Workbook | Forensic Schedule Workbook | — |
| Index | Supporting Documents Index | — |
A-05
Entitlement Summary
register · per-window working daysA-05Entitlement Summary: every claimed window listed
2 rows — all listed (incl. total)Export CSV
| Exhibit | Window | Description | Working Days |
|---|---|---|---|
| DE-01 | Baseline → Current | Fire-spray application held for owner inspector availability | 9 WD |
| — | TOTAL CLAIMED | 9 WD |
A-06
Contract Basis
entitlement clausesEntitlement Basis
The Contractor claims 9 working days pursuant to GC 6.5.1 (delay by the Owner or the Consultant) of the demonstration contract. Clause citations follow the demonstration contract and are stated for format; this is synthetic data.
Impacting Events
- Fire-spray application held for owner inspector availability.
- Total critical-path impact: 9 working days.
Response Required
- Formal written response requested within 30 days per contract.
- Contact the undersigned to schedule a discussion meeting.
A-06Contract Basis: event to clause map (all events listed)
1 event — all listedExport CSV
| Exhibit | Event | Contract Clause(s) |
|---|---|---|
| DE-01 | Fire-spray application held for owner inspector availability | GC 6.5.1 (delay by the Owner or the Consultant) |
A-07
Closing and Signature
request · undersigned01Requested ActionResponse · 30 Days
We request a formal written response to this claim within 30 days in accordance with the contract. Please contact the undersigned with any questions or to schedule a meeting to discuss this submission. Respectfully submitted.
02UndersignedClaimant Signatory
Dana Fitkowski, Principal, Critical Path Partners, Northgate Constructors
A-08
Distribution and Provenance
CC list · package manifestCC Distribution
Project file
Delay Event Analyses
1 analysis
Forensic Workbook
Schedule workbook included
Supporting Docs Index
5 documents
Contract Reference
CCDC 2 - 2020, Contract No. OCC-B2-2025 (Demo Data)
Submission Date
2026-09-01
Generated by CPP Claims Preparation · Project: Ontario Community College - B2 (Demo Data) · Claimant: Northgate Constructors · Engine cpm-engine v2.9.42Reproducible · standards-based